Picture of Ontario Renovation Contract Picture of Ontario Renovation Contract Picture of Ontario Renovation Contract

Ontario Renovation Contract

Ontario contractors, write up a Renovation Contract for a home owner with this easy-to-use template form.

  • Materials. The contractor agrees to provide all required materials, labor, tools, equipment and supervision.
  • Contract Price. Payment of the contract price, less required holdback under the Ontario Construction Lien Act, will be made in several payments, with the balance due on completion.
  • Change Orders. A signed change order is required for any alterations to the work specified.
  • Site Safety. The contractor is responsible for cleanup and for job site safety.
  • Home Owner's Responsibilities. The home owner is responsible for providing utilities, toilets and access to the work site.
  • Warranty. The contractor provides a 1-year warranty of the materials and workmanship and agrees to correct any defects of which it is notified in writing during the warranty period.
  • Insurance. The contractor is responsible for maintaining adequate insurance, and for complying with the requirements of the Workers Compensation Act.
  • Available in MS Word format.
  • Intended to be used only in the Province of Ontario, Canada.
Document Type: Microsoft Word
Last Updated: 01-February-2022
SKU: 5847
$29.99
Related products
Picture of Basement Renovation Price Quote and Contract

Basement Renovation Price Quote and Contract

Write up a price quote for a basement renovation with this template form, which becomes a binding contract when signed by both parties.

  • Fully editable so you can customize it for your business.
  • Includes scope of work, exclusions, draw dates, and other terms and conditions.
  • The template can be firstly as a price quotation, and when agreed to in writing by both parties, it becomes the renovation contract.
  • Buy, download and use it as often as you like.
  • This Basement Renovation Price Quote and Contract form is available in Microsoft Word format.
$12.49
Picture of Waiver and Release of Homeowner by Contractor | Canada

Waiver and Release of Homeowner by Contractor | Canada

If you hire a contractor to do work on your home, protect yourself against claims arising from injury or death with this Canada Waiver and Release of Homeowner by Contractor.

  • The Waiver and Release form should be signed before the contractor starts work on the construction or renovation project.
  • The contractor releases the property owner from any and all liability, and acknowledges the risks associated with the construction.
  • The contractor assumes all responsibility and waives any claims he/she may have with respect to injury, damage or loss resulting from the performance of the work.
  • This form is available in MS Word format and is fully editable to fit your specific circumstances.
  • Intended to be used only in Canada.
$5.99
Picture of Construction Contractor Agreement with Late Completion Penalty

Construction Contractor Agreement with Late Completion Penalty

Are you hiring a contractor to do construction or renovation work to your property? Keep the project on schedule with this Construction Contractor Agreement with Late Completion Penalty.

  • The contractor agrees to substantially complete the work by a specified completion date agreed to by both parties.
  • If the contractor fails to complete the work by the completion date, the contractor will pay a penalty for each day ⁄ week that the work remains unfinished.
  • Alternatively, if the work is completed ahead of schedule, the contractor will be paid a bonus.
  • This is a generic (not country specific) legal contract form.
This Construction Contractor Agreement with Late Completion Penalty is an editable MS Word template which can be easily customized to fit your needs.
$12.49
Picture of Contract Change Order

Contract Change Order

Prepare a Contract Change Order for changes under a construction or renovation contract with this easy-to-use template form.

  • The Change Order form must be signed by both the owner and the contractor, and the owner may require the contractor's surety (if any) to approve the changes as well.
  • The changes can include additions, amendments or deletions to the scope of the work, materials, extras, etc., and corresponding adjustments to the contract price.
  • The completion date can also be amended to accommodate the changes.
  • The Change Order form can be used by general contractors and subtrades alike.
  • This is a generic form that can be used anywhere.
$2.99
Customers who bought this item also bought
Picture of Construction Contractor Agreement | Canada

Construction Contractor Agreement | Canada

Prepare a Construction Contractor Agreement for a residential construction project in Canada with this easy-to-use template.

  • The contract price for the construction will be paid in installment payments.
  • All labour, tools, equipment and materials required for the job will be provided by the contractor.
  • The property owner must arrange for water, sewer, electrical, natural gas, and other utility hook-ups required to complete the work.
  • The contractor is responsible for carrying adequate liability insurance for the duration of the project.
  • This is a fully editable and reusable contract template intended for use only in Canada.
$12.49
Picture of Waiver and Release of Homeowner by Contractor | Canada

Waiver and Release of Homeowner by Contractor | Canada

If you hire a contractor to do work on your home, protect yourself against claims arising from injury or death with this Canada Waiver and Release of Homeowner by Contractor.

  • The Waiver and Release form should be signed before the contractor starts work on the construction or renovation project.
  • The contractor releases the property owner from any and all liability, and acknowledges the risks associated with the construction.
  • The contractor assumes all responsibility and waives any claims he/she may have with respect to injury, damage or loss resulting from the performance of the work.
  • This form is available in MS Word format and is fully editable to fit your specific circumstances.
  • Intended to be used only in Canada.
$5.99
Picture of Construction Project Management Agreement | Canada

Construction Project Management Agreement | Canada

Hire a project manager for a large development project with this fixed price Construction Project Management Agreement for Canadian developments.

  • The project manager will manage and coordinate activities among the various contractors hired on the construction project.
  • The project manager will be responsible for obtaining bids and making recommendations with respect to hiring.
  • The manager will assist in obtaining the necessary permits for the development.
  • The manager must review all contractor safety programs.
  • The manager's duties specifically do NOT include control over the practices of the contractors.
  • The owner indemnifies the project manager against all claims and losses arising from the performance of its duties.
  • Available in MS Word format and fully editable.
  • Intended to be used only in Canada.
$12.49
Picture of Contract Change Order

Contract Change Order

Prepare a Contract Change Order for changes under a construction or renovation contract with this easy-to-use template form.

  • The Change Order form must be signed by both the owner and the contractor, and the owner may require the contractor's surety (if any) to approve the changes as well.
  • The changes can include additions, amendments or deletions to the scope of the work, materials, extras, etc., and corresponding adjustments to the contract price.
  • The completion date can also be amended to accommodate the changes.
  • The Change Order form can be used by general contractors and subtrades alike.
  • This is a generic form that can be used anywhere.
$2.99
Picture of Fixed Price Construction Contract with Warranty | Canada

Fixed Price Construction Contract with Warranty | Canada

Canadian contractors, use this template to prepare a Fixed Price Construction Contract with Warranty for Canada.

  • The contract includes a warranty by the contractor on materials and labour used in the construction.
  • The contractor is responsible for Workers Compensation, public liability and property damage insurance, and all perils insurance, and indemnifies the owner against claims arising as a result of the contractor's operations.
  • Changes to the work which are not included in the Construction Contract will be on the basis of either (i) a stipulated sum or (ii) actual cost plus a percentage.
  • Disputes will be submitted first to the architect, and failing settlement, to arbitration.
  • The contract is available as a fully customizable MS Word document.
  • Intended to be used only in Canada.
$17.99