Wisconsin Notice of Intent to File Lien Claim - Prime Contractor

Preserve your lien rights for work done on a property in Wisconsin with this Prime Contractor Notice of Right to File Lien form.

Why do I need the Notice of Right to File Lien form?

Under Wisconsin law, the prime contractor on a construction project must give notice to the property owner that a lien may be filed on the property by any party which is not paid in full for furnishing goods, labor or services for the improvements.

Features of Document Template

• The form includes instructions on how to file and serve the Notice.
• Buy the form once, and it's yours to use as often as you require.
• Available in MS Word format and easy to download, fill in and print.

Legal Jurisdiction

This Prime Contractor Notice of Right to File Lien template was prepared in accordance with the Wisconsin Construction Lien Law and should only be used within that State.

WI contractors, file your lien claims with this Wisconsin Prime Contractor Claim for Lien form.

• The prime contractor claims a lien for goods, labor and ⁄ or services provided for improvements to the property identified in the lien claim.
• The form includes instructions on how to serve the Claim.
• Buy the form once, and it's yours to use as often as you require.

Prepare a Contract Change Order for changes under a construction or renovation contract with this easy-to-use template form.

• The Change Order form must be signed by both the owner and the contractor, and the owner may require the contractor's surety (if any) to approve the changes as well.
• The changes can include additions, amendments or deletions to the scope of the work, materials, extras, etc., and corresponding adjustments to the contract price.
• The completion date can also be amended to accommodate the changes.
• The Change Order form can be used by general contractors and subtrades alike.
• This is a generic form that can be used anywhere.

WI contractors, has your lien claim been settled? File and serve this Wisconsin Full Satisfaction of Claim for Lien.

• The Satisfaction form authorizes the Court Clerk to enter satisfaction of the claim on the lien docket.
• The form includes a copy of Section 779.13 of the Wisconsin Statutes for your reference.
• Buy the form once, and it's yours to use as often as you require.

WI subcontractors, preserve your lien rights by filing and serving this Subcontractor Identification Notice under Section 779.02(2)(b) of the Wisconsin Statutes.

• The Notice is issued by a subcontractor to notify a property owner that the subcontractor will be supplying labor or materials for the owner's property under a contract with the prime contractor on the project.
• Buy the form once, and it's yours to use as often as you require.