Products tagged with 'construction contract form'

Insert these optional additional clauses into a construction contract to cover procedures for shortages and substantard work and materials.

• These provisions give the project engineer the authority to deal with:
  • defective work or materials,
  • shortages of materials,
  • labor shortages.
• These contract clauses can be downloaded in MS Word format.
• These are generic clauses that do not make reference to any specific state, provincial or federal laws and can be used in many jurisdictions.

Canadian contractors, use this template to prepare a Fixed Price Construction Contract with Warranty for Canada.

• The contract includes a warranty by the contractor on materials and labour used in the construction.
• The contractor is responsible for Workers Compensation, public liability and property damage insurance, and all perils insurance, and indemnifies the owner against claims arising as a result of the contractor's operations.
• Changes to the work which are not included in the Construction Contract will be on the basis of either (i) a stipulated sum or (ii) actual cost plus a percentage.
• Disputes will be submitted first to the architect, and failing settlement, to arbitration.
• The contract is available as a fully customizable MS Word document.
• Intended to be used only in Canada.

Insert these optional additional clauses into a Construction Contract for a commercial building project, to make provisions for the following matters:

• onsite control by the engineer,
• hiring a site foreman,
• security,
• conduct of employees,
• loss or damage to work,
• provision of utilities and services,
• delivery and storage of materials,
• cleanup of work site.

These generic Construction Contract Clauses for Commercial Building Project are available in MS Word format, and are not specific to any country or region.

Write up a price quote for a basement renovation with this template form, which becomes a binding contract when signed by both parties.

• Fully editable so you can customize it for your business.
• Includes scope of work, exclusions, draw dates, and other terms and conditions.
• The template can be firstly as a price quotation, and when agreed to in writing by both parties, it becomes the renovation contract.
• Buy, download and use it as often as you like.
• This Basement Renovation Price Quote and Contract form is available in Microsoft Word format.

Set out the terms and conditions for construction of a residential single-family dwelling with this Short Form Construction Contract for USA building contractors.

• The contractor will furnish labor and materials and build the structure according to the approved plans.
• The owner is responsible for arranging building permits, access to the work site, utilities hook-ups, and compliance with zoning requirements.
• The contract price will be paid in several installments.
• The owner must arrange financing and having the site prepared for construction (surveying, staking, excavation, etc).
• The contract template does not contain any State-specific references or language. Those can be easily added if required.
• Writing your project agreements is easy with the USA Short Form Construction Contract. Download the template now.
• Intended to be used only in the United States.

Prepare a Contract Change Order for changes under a construction or renovation contract with this easy-to-use template form.

• The Change Order form must be signed by both the owner and the contractor, and the owner may require the contractor's surety (if any) to approve the changes as well.
• The changes can include additions, amendments or deletions to the scope of the work, materials, extras, etc., and corresponding adjustments to the contract price.
• The completion date can also be amended to accommodate the changes.
• The Change Order form can be used by general contractors and subtrades alike.
• This is a generic form that can be used anywhere.